Acceptance of Terms
By accessing this website or requesting any of our home improvement, maintenance, renovation, or repair services, you acknowledge that you have read, understood, and agree to be legally bound by these Terms & Conditions. If you do not agree with any part of these terms, please discontinue use of our website and services immediately.
Eligibility
Our services are intended for individuals who are at least 18 years of age and legally capable of entering into binding contracts under applicable United States law. By using our services, you represent that you meet these eligibility requirements.
Scope of Services
We provide residential and commercial home improvement services including, but not limited to, remodeling, renovations, painting, flooring, roofing, plumbing, electrical work, landscaping, cleaning, maintenance, inspections, and related services. All services are performed according to the written proposal or service agreement approved by the customer.
Project Estimates
Estimates, quotations, and consultations are provided based on the information available at the time of inspection or customer inquiry. Final pricing may change if unforeseen site conditions, additional work, material price fluctuations, code requirements, or customer-requested modifications arise during the project.
Customer Responsibilities
Customers agree to provide accurate contact information, grant reasonable access to the property during scheduled work hours, remove valuables or fragile items from work areas, secure pets, and disclose any known safety concerns or hazardous conditions before work begins.
Permits and Inspections
Where required by local building regulations, permits and inspections may be necessary before or during project completion. Permit responsibilities will be determined in the project agreement unless otherwise specified in writing.
Scheduling and Delays
Project schedules are estimated and may change due to weather conditions, material availability, supplier delays, labor shortages, emergencies, government restrictions, inspections, or other circumstances beyond our reasonable control. We will make reasonable efforts to communicate scheduling changes promptly.
Pricing and Payment Terms
Payment schedules, deposits, milestone payments, and final balances are outlined within each individual project agreement. Payments not received by the agreed due date may be subject to applicable late fees, interest charges, suspension of work, or collection procedures permitted by law.
Change Orders
Any modifications to the agreed project scope, materials, design, labor requirements, or completion schedule must be approved in writing before additional work begins. Approved change orders may result in additional charges and revised project timelines.
Materials and Product Availability
Material selections are subject to manufacturer availability. If specified products become unavailable, we may recommend comparable alternatives after discussing available options with the customer whenever reasonably possible.
Property Access
Customers are responsible for providing safe and uninterrupted access to the work site throughout the duration of the project. Delays caused by restricted access, unavailable utilities, locked premises, or unsafe working conditions may result in additional scheduling adjustments or service charges.
Safety
For safety reasons, customers should keep children, pets, and unauthorized individuals away from active work areas. We reserve the right to suspend work if unsafe conditions exist that may endanger workers, customers, or property.
Warranty
Workmanship warranties, where offered, apply only to services specifically identified within the project agreement. Warranty coverage excludes normal wear and tear, customer misuse, neglect, accidental damage, unauthorized repairs, natural disasters, improper maintenance, and issues resulting from work performed by third parties.
Limitation of Liability
To the fullest extent permitted by applicable law, our total liability arising from any claim related to our services shall not exceed the amount actually paid by the customer for the specific services giving rise to the claim. We shall not be liable for indirect, incidental, special, consequential, punitive, or economic damages, including loss of profits, business interruption, or property value.
Force Majeure
We shall not be responsible for delays or failure to perform resulting from events beyond our reasonable control, including severe weather, floods, fires, pandemics, labor disputes, supplier shortages, utility failures, governmental actions, transportation disruptions, or other force majeure events.
Website Use
Users agree not to misuse this website, interfere with its operation, attempt unauthorized access to any systems, upload malicious software, transmit unlawful content, or engage in activities that may damage our website or services.
Intellectual Property
All website content, including text, photographs, graphics, logos, icons, videos, layouts, and design elements, remains our exclusive intellectual property unless otherwise stated. No content may be copied, reproduced, distributed, modified, or republished without prior written permission.
Third-Party Links
Our website may include links to third-party websites for informational purposes. We do not control or endorse these external websites and are not responsible for their content, security, privacy practices, or services.
Termination
We reserve the right to suspend or terminate services if customers violate these Terms & Conditions, fail to make required payments, provide misleading information, create unsafe working conditions, or otherwise breach the project agreement. Customers may also terminate services according to the cancellation provisions contained in their written agreement.
Indemnification
Customers agree to indemnify and hold harmless our company, employees, contractors, and affiliates from any claims, liabilities, damages, expenses, or legal costs arising from misuse of our services, customer-provided information, property conditions beyond our control, or violations of these Terms & Conditions.
Privacy
Your use of our website is also governed by our Privacy Policy, which explains how personal information is collected, used, stored, and protected. By using our services, you acknowledge that you have reviewed our Privacy Policy.
Modifications to These Terms
We reserve the right to update or revise these Terms & Conditions at any time without prior notice. Updated versions become effective immediately upon publication on this website. Continued use of our website or services constitutes acceptance of the revised terms.
Governing Law
These Terms & Conditions shall be governed by and interpreted in accordance with the applicable laws of the United States and the state in which our services are provided, without regard to conflict of law principles. Any dispute arising from these Terms or our services shall be resolved through negotiation, mediation, binding arbitration, or a court of competent jurisdiction, as permitted by applicable law.
Severability
If any provision of these Terms & Conditions is determined to be invalid, illegal, or unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect.
Entire Agreement
These Terms & Conditions, together with any written project proposal, service agreement, invoice, and Privacy Policy, constitute the complete agreement between the customer and our company regarding the services provided.
Contact Information
If you have any questions regarding these Terms & Conditions, please contact our customer support or legal team using the contact information provided on our website.